VALUE OF THE CONTRACT (Rs. in Lakhs) BRIEF DETAILS OF THE MATERIALS PROCURED. Price agreement for supply of BEML spares STE

Transcription

1 NEYVELI LIGNITE CORPORATION LIMITED, NEYVELI STATEMENT SHOWING QUARTERLY PROGRESS OF SUPPLY/PURCHASE S FOR QUARTER ENDING SEPTEMBER CATEGORY - I : 5 Crore and above SL. NAME OF NO. BRIEF DETAILS OF BEML Limited PO/10-11/005313/ENQ/10-11/002994/MM03(01) Price agreement for supply of BEML spares STE 365 Days price agreement valid till Part supply. Short closure proposal under porcess. 2 TELCO CONSTRUCTION EQPT CO LTD PO/11-12/003285/ENQ/11-12/001143/MM03(01) Spares for TATA HITACHI hydraulic excavotors and shovels as per company's price list LTE 365 days Part supply. Short closure proposal under porcess. 3 BHARAT PETROLEUM CORPORATION LTD PO/11-12/005382/TC/ENQ/11-12/003345/MM18(05)/10/11 PO DATE High speed diesel oil LTE 365 days delivery date ( ) Part Supply. Short closure under process. 4 M/s. Indian Oil Corporation Ltd PO/11-12/005383/TC/ENQ/11-12/003345/MM18(05)/10/11 PO Date :09/03/2012 High speed diesel oil LTE 365 days. date ( ) Part Supply. Short closure under process. 5 M/s. Hindustan Petroleum Corporation Limited PO/11-12/005384/TC/ENQ/11-12/003345/MM18(05)/10/11 PO Date :09/03/2012 High speed diesel oil LTE 365 days. date ( ) Part Supply. Short closure under process. 6 M/s.Phoenix Conveyor Belt India (P) Limited PO/12-13/002209/TC/ENQ/11-12/004203/MM02(04)/49/1 PO Date :04/08/ mm wide steel cord belt ST 4000 with top cover 14mm and bottom cover 10mm GTE 365 days delivery ( ) Part Supply. 7 M/s. Premier Explosives Ltd., Secunderabad PO/12-13/005123/TC/ENQ/12-13/001710/MM18(03)/36/21. PO date: Cast Booster (100 gms), Cast Booster (250 gms) Site Mixed Explosive High Strength. SME Nominal Strength LTE 1095 Days. date: Part supply 8 M/s. Vetrivel Explosives Pvt Ltd., Salem PO/12-13/005124/TC/ENQ/12-13/001710/MM18(03)/36/21. PO date: Cast Booster (100 gms), Cast Booster (250 gms) Site Mixed Explosive High Strength. SME Nominal Strength LTE 1095 Days. date: Part Supply 9 Bharath Petroleum Corporation Ltd Chennai PO./12-13/006361/TC/ENQ/12-13/003408/MM18(05)/10/11 PO Date: High speed diesel oil LTE Completion Date ( ) Part Supply. Short closure under process.

2 NAME OF NO. BRIEF DETAILS OF 10 M/s. Hindustan Petroleum Coporation Ltd. PO/12-13/006362/TC/ENQ/12-13/003408/MM18(05)/10/11. PO date: High speed diesel oil LTE 365 days. date ( ) Part Supply. Short closure under process. 11 M/s. Indian Oil Corporation Ltd PO/12-13/006363/TC/ENQ/12-13/003408/MM18(05)/10/11. PO date: High speed diesel oil LTE 365 days. date ( ) Part Supply. Short closure under process. 12 BHARAT PETROLEUM CORPORATION LTD PO/13-14/002922/TC/ENQ/13-14/000902/MM18(05)/10/11. DT Light diesel oil IS:1460/ LTE 365 Days Part supply. 13 Hindustan Petroleum Corporation Limited PO/13-14/002925/TC/ENQ/13-14/000875/MM18(04)10/11 DT Furnace oil conforming to IS:1593/ LTE 365 Days Part supply. 14 BHARAT PETROLEUM CORPORATION LTD PO/13-14/002924/TC/ENQ/13-14/000875/MM18(04)/10/11 DT Furnace oil conforming to IS:1593/ LTE 365 Days Part supply. 15 Regenesis Industries Private Limited PO/13-14/005167/TC/ENQ/13-14/002062/MM18(3)/36/21 PO Dt High Strength Catridge Type Explosives 125MM DIA PTE 730 Days. Completion Date ( 18/09/2014) Part Supply 16 Hindustan Petroleum Corporation Limited PO/13-14/006453/TC/ENQ/13-14/003841/MM18(05)/10/11 PO Dt High speed diesel oil LTE date Part supply. 17 Indian Oil Corporation Limited PO/13-14/006454/TC/ENQ/13-14/003841/MM18(05)/10/11 PO Dt High speed diesel oil LTE Completion date Part supply. 18 Bharath Petroleum Corporation Ltd Chennai PO/13-14/006455/TC/ENQ/13-14/003841/MM18(05)/10/11 PO Dt High speed diesel oil LTE date Part Supply. 19 Phoenix Conveyor Belt India Ltd., PO/14-15/002206/TC/ENQ/13-14/004889/MM02(04)/49/1 PO Date: Steel Cord conveyor Belting 2400MM Wide GTE 240 Days. Delively date 11/04/2015 Supply completed.

3 NAME OF NO. BRIEF DETAILS OF 20 Thyssenkrupp Industrial solutions PO/14-15/003747/TC/ENQ/14-15/001860/MM01/(05)/46/1 PO Dt KV BW GB complete assembly for 700 BWE STE 450 Days. date Nil Supply. 21 Tusker Cranes Private Limited PO/14-15/005656/TC/ENQ/13-14/002993/MM22(01)/23/1 PO Date Hydraulic crawler crane of 100 Ton PTE 455 Days. Delivey Nil Supply. Date ( ) 22 BHARAT PETROLEUM CORPORATION LTD 23 Indian Oil Corporation Limited PO/14-15/005431/TC/ENQ/14-15/004090/MM18(05)/10/11 PO Date PO/14-15/005655/TC/ENQ/14-15/004090/MM18(05)/10/11 PO Date High speed diesel oil LTE High speed diesel oil LTE Completion date Completion date Part supply. Part supply 24 Hindustan Petroleum Corporation Limited PO/14-15/005654/TC/ENQ/14-15/004090/MM18(05)/10/11 PO Date High speed diesel oil LTE Completion date Part supply 25 Ansaldo Energia SPA Genova PO/14-15/005654/TC/ENQ/14-15/002677/MM02(07)/49/1 PO Date Mechanical Spares STE 270 days. Date Nil supply 26 Forech India Ltd. Kolkata PO/14-15/000598/TC/ENQ/14-15/002495/MM05(03)/1/20 PO Date MM conveyor Steel cord belt, ST GTE 240 DAYS date Part supply 27 Tyazhmash, Syzran PO/14-15/001235/TC/ENQ/14-15/003560/MM04(02)/82/5 PO Date Beater wheel without beater plates and armouring (CCW) Beater wheel withour beater plates and armouring (CW) STE 300 DAYS. Delivey date Nil supply 28 Vetrivel Explosives Pvt Ltd., PO/15-16/001690/TC/ENQ/14-15/003790/MM18(03)/36/21 PO dt Cast Booster site mixed explosive high strength PTE 1275 DAYS. date ( ) Nil supply.

4 NAME OF NO. BRIEF DETAILS OF 29 Premier Explosive Ltd., 30 TNS Heavy Engineering Pvt ltd 31 Steel Authority of India Ltd. 32 M/s. Gammon (I) Ltd. PO/15-16/001691/TC/ENQ/14-15/003790/MM18(03)/36/21 PO dt PO/15-16/002561/TC/ENQ/14-15/002496/MM02(08)/49/1 PO dt PO/15-16/002679/TC/ENQ/14-15/004651/MM02(03)/49/1 PO dt LOA 0014H/TSII.Ex./A06/ CT/04 dt Cast Booster site mixed explosive high strength. 1600mm conveyor standard frames PTE PTE UIC-60 Rails T PTE NDCTS & RCC chimney PTE 1275 Days. dt DAYS. dt DAYS. dt months from Part Supply. Nil Supply Nil supply. CT-I: completed and was teken into service. Trial operation of cooling tower 1 is completed. PG test is pending. CT-II: Taken in to service on Trial operation & PG tests are pending. Chimney taken into service. 33 M/s.Mecon, Ranchi LOA 0016H/TS II Ex./ A 02 /CT/04, Dt: Lignite Handling System PTE Trial operation and PG test is to be conducted. To be conducted after main plant package is made ready. 34 M/s Mc Nally Bharat Engg. Co. LOA 0024H/HTSII Expn./A03/CT/2004, Dt: TPS-II Expn. (2 x 250 MW) Ash Handling system (A03) Package Phase-I Lakhs PTE 24 months from ( ). Unit I initial operation completed on Unit II work initial operation completed on PG test to be taken up. EOT upto & upto for of initial operation for Unit I & II respectively without LD granted. Trial operaion for Unit I commenced on and 25 days out of 30 days, have been conducted Traial operation & PG test for Unit ii can be carried out only after Unit II is put up into regualr operation. EOT upto was granted for conducting trial operation and PG test of Unit I and II of AHS as per terms and condition of contract. 35 M/s BHEL (Transmission Business Group), New Delhi LOA 0011H/TS II Ex./ A08/CT/2004, Dt KV Switchyard & Power transformer 8411 PTE EOT given upto for PG test. PG test yet to be completed. 36 M/s Driplex Water Engg. Ltd. LOA 0022H/TS II Ex./ WTP/ A05/CT/04, Dt: Supply, erection & commissioning of Water Treatment Plant & Effluent treatment Plant 6272 PTE Warranty period of PT & softening plant and RO DM plant was over and the 2 systems were taken over. Note for EOT without LD upto for the other three plants are under circulation.

5 NAME OF NO. BRIEF DETAILS OF 37 M/s.BHEL, New Delhi LOA 0006H/ A01/ CT/04, Dt: TPS II Expn. (2 x 250 MW) Main Plant Package (Boiler, Turbo Generators & their auxiliaries) Rs US$21,016,0 00 Euro 40,000,000 Global 39 & 43 months from LOA for PG test of UNIT I & II respectively for PG tests LOA dt Work in progress. EOT granted with right to levy LD upto for trial operation and upto for PG test. Commercial operation was declared on for Unit II and on for unit I. 38 M/s. Tecpro Ashtech Ltd., Pune. LOA 0028H/BPP/RA2/CT/04, Dt: BPP at Rajasthan (2 x 125 MW) Ash Handling System (RA3 package) 2447 PTE 26 months from ( ) 94%. EOT without levy of LD granted upto to complete works related to PG test activities and conduct PG test of both units I & II. The firm vide letter dated have agreed to conduct PG test in June 2015 and the same was informed to the competent authority. 39 M/s Subash Projects and Marketing Ltd, (SPML) Kolkatta-16. Cont /0017H/ TSII Expn./A04/ Conts. Thermal/04, Dt: Circulating Water System and Fire Protection System A PTE 32 Months from the date date of LOA ( ) EOT granted upto for of whole of works in FPS & CWS (without prejudice to the extension given for trail operation of U1 CWS & U2 CWS upto & respectively and FPS upto with levy of LD.) 40 M/s BHEL, New Delhi LOA Co/Conts./ 0014K & 0015K/NTPL/ TTPP/07, Dt (Both tenders combined in to single order) Steam Generator unit ESP package (TA1-SG) & Steam Turbine Generator Package (TA1-TG) ICB Work in progress. EOT given with a right to levy LD upto and for Unit 1 and II trial operation respectively. Unit -I &II commercial operation declared on and respectively. 41 M/s BCL FGM Consortium, New Delhi Contract CoConts/007M/BLMP/ Lig./OS/2008, Dt Lignite Excavation. Hiring of Crawler Mounted Shovels / Hyd Exe Backhoes, Dumpers at Barsingsar Lignite Mines 9086 PTE 7 years 43.19%. Lignite excavation under progress. Board in its meeting held on accorded approval for extension of contract two years upto under same terms and condtions. 42 M/s.L&T Ltd M/s.Kirloskar Brothers Ltd Pune M/s.Larsen & Toubro Ltd, Chennai LOA No Co/Conts/0022K/NTPL /TTPP/TA2/2007, LOA Co CONTS/0038 K/NTPL/TYTPP/TA4/08, Dt: LOA NoCo Conts/0026K/NTPL/ TTPP/TA8/2007, Dt: Coal Handling System for NTPL Rs ( ) USD GTE Circulating Water systems PTE 400 KV SWGR SwitchYard & 220 KV SWGR Switchyard (USD ) (Euro 70348). 39 Months from LOA 34 months from LOA 24 months from LOA Work under progress. EOT given upto & for stream A & Stream B with right to levy LD and the initial operation has been completed for both stream 99.35% work completed as on EOT for of PG test for Unit I on Unit II upto was granted as per the terms and conditions of the contract. EOT granted upto for commissioning of 400 KV GIS & 220 KV GIS switch yard of Unit I & II without prejudice to the time extension already granted upto with a right to levy LD for mechanical.

6 NAME OF NO. BRIEF DETAILS OF 45 M/s.Energo Engg.Projects Ltd.,New Delhi LOA 0031M/HTSII Expn./A03/Ph-II/CT/08, Dt: Ash Handling System (A03) Phase-II, TPS-II Expn PTE 15 months from LOA Work in progress. Resolution obtained for EOT upto with right to levy LD to complete initial operation of AHS. Legal vetting note is under circulation.tion of AHS was granted. 46 M/s Asia Power Project Pvt Ltd, Chennai Unit 2 Major overhaul of HP,IP- LP Turbine & Generator and replacement of IP-LP rotar and 215/GM/TPS-I NDT of L-0, L-1 steeples & Expn/cont/2500/TM/T.NO.12/(15- blades IP-LP rotor to be 16) LOI 2015 Dt removed from Unit - 2 (210MW) at TPS 1 expn during the period Within 36 Calendar days from the date of stopping to starting of the barring gear. 0%. Tentative scheduled date of shut down of the unit is 4th Nov M/s ABB Ltd., Chennai Contract /Coconts/0028K/NTPL/T TPP/TA 9/07/DT Power Transformer package (TA9) for TTPP (2x500MW) Project at Tuticorin PTE 34 months from LOA ( LOA DT ) Work is in progress. EOT granted upto with levy of LD for commissioning and upto for of PG test. Note initiated by site for seeking for further. EOT upto is under circulation. 48 M/s.Energo Engg.Projects Ltd.,New Delhi LOA Co.Cons/0023 M/NTPL/TTPP/TA-3/2008, Dt: Ash Handling Plant & Auxillaries Package (TA3) GTE 22 & 27 months from date of LOA Work in progress. EOT given upto for unit I for unit-i & II & upto for Unit II with right to levy LD. Resply. 49 M/s.Gammon India Ltd., Mumbai LOA CoConts/0029K/NTPL/ TTPPTA6/2007, Dt: Nos Draft Cooling Tower for NTPL Project PTE 33 months from LOA Work is in progress. EOT given upto & for cooling tower - 1 and 2 respectively M/s. Tecton Engineering & Construction LLC Agman, UAE M/s Takraf (I) India Pvt Ltd., Chennai Co. Conts/ 0014M/NTPL/TTPP/ TA5/ 2008, Dt: LOA.NO. Co.Conts/0003B/MIA/ MTC/2014 dt Desalination Plant and Water Treatment Plant Package (TA 5) for Tuticorin Thermal Power Project. Procurement of 1 no of MTC of capacity 994 M3/hr for MIA Rs USD GTE GTE 19 months from LOA Months from date of LOA Work is under progress. EOT given upto with right to levy LD. Note for further EOT upto is under circulation. Work under progress. 52 M/s Mahalakzhmi Infra Co Ltd. Ahamedabad LOA Co.Conts/0004C/MII/ OBR/CM/ 15 Dt Hiring of equipment for removel of 80 L on OB in Mine II PTE 24 moths from ( Work under progress ) 53 M/s Sify Technology Ltd. Chennai LOA Co.Conts/0032C/CS/ MDVES/15 Dt Supply, installation and commissioning of Multi print HDVES at Chennai, Neyveli Tuticorin and Barsingsar including 5 year AMC PTE 90 days from the date of LOA ( ) LOA issued on

7 NAME OF NO. BRIEF DETAILS OF 54 M/s Takraf India Pvt Ltd. Chennai LOA Co. Conts/0016B/MI/ BWE/2014 Dt Procurement of 1 no BWE of 700L Capacity PTE 36 Months from ( ) work under progress. 55 M/s BGR Mining & Infra Pvt Ltd., Hydrabad LOA Co.conts/0001C/ MIA/OBR/15 dt Removal of overburden excavation of 65.6 MM3 at MIA PTE 48 months from work under progress 56 M/s Building automation Pvt Ltd. Chennai LOA Renovation of fire alarm system Co.Conts/0033B/RFAS/TPS II/14 TPS II Dt PTE Commissioning - 16 months from LOA. Pef & LOA ISSUED on Acceptances -18 months from LOA M/s. DEE Tech Projects Pvt. Ltd M/s Abiram Infra projects, Hydrabad 59 M/s. Jyothi Limited, Vadodara LOA. CoConts/042P/ NTPL/ TTPP/GWC/ SWP/TC/3B dt LOA NoCo Conts/0010RNTPL/ NRB/2011 DT LOA CoConts/0041P/ NTPL/TC2A/2010 Dt Storm water pumping Arrangements for NTPL Construction of non- residential buildings for NTPL township at Tuticorin Circulating water System and outfall system 1192 PTE PTE 3855 PTE 12 months from 18 months from the date of handing over of site 12 months from Work in progress EOT given upto with right to levy LD. The work front is handed over to the firm on Work is in progress. EOT given upto with right to levy LD. EOT upto was granted with a right to levy LD as per provision of the contract. 90% work completed as on M/s Mather & Platt Pumps Ltd, Mumbai LOA Coconts/ 0026P/NTPL/ TTPP/ TD1/2010, DT Fire protection system package (TD1) for NTPL Power Project PTE 20 & 25 months for of PG test of Unit I & II respectively from date of LOA Work in progress. EOT given upto with right to levy LD for trial operation of Unit I & II and upto for PG test. 61 M/s. TRF Limited LOA. CoConts/0004R/ NTPL/ TTPP/Sh Unloader/2011 dt Shore Unloader 2 Nos TPH 8622 ICB 18 months from LOA EOT granted upto for initial operation of SUL -2 with right to levy LD and upto for SUL -1 to complete pending works without prejudice to the time extension granted upto with right to levy LD for of initial operaion. 62 M/s.Wipro Limited LOA CoConts/0007T/ CO/DC&DR/2012, dt Establishing Data Centre & Data recovery centre along with SAP- ERP PTE 12 months from Work in progress. EOT given upto , with right to levy LD. Note for EOT upto under circulation. 63 M/s BHEL, Bangalore DCS (Distribution control system CO/Conts/0010T/TS-II-ST- ) implementation in state II units II/DCS/IMP/2012 Dt (4x210 MW) of TS-II at Neyveli months from Detailed Engg. Is in progress. Civil works is under progress.

8 NAME OF NO. BRIEF DETAILS OF 64 M/s. Sical Logistics Ltd, Chennai LOA CoConts/0017P/NTPL/ CWALCont. Thermal/10 dt Transportation of Coal from MCL to Tuticorin Port via Port Praradip PTE 54 months from LOA or 36 months from supply of Coal by M/s.NTPL, whichever is earlier Supply of Coal by NTPL is likely to be started in Oct M/s Leitwind shriram Mfn. Chennai LOA CO CONTS/0006T/Wind Farm/2012 Dt Procurement of Land Design, Manufacture, supply, erection, testing commissioning, synchronization with grid, Handing over, Guaranteeing, of 51Mw wind farm complete at Kaluneerkulam Tamil Nadu and O&M O&M 1462 PTE 10 Months from LOA and 5 years from commissioning. So far 68% work completed. Nine of Wind Mill commissioned, time extension given upto with right to levy LD. 66 M/s L&T Chennai Procurement of 2 nos 700 Lit LOA NO. CO CONTS/0001A/ BWEs for Mine I & Mien-II and MIA&MI IBWE/2013 Dt maintenance O&M Euro 99,65, GTE within 36 months (i.e ) 100% Mechanical ( Imported) and 98.5% ( Indigenour) supplies completed. Erection under progress. 67 M/s BHEL LOA CoConts/0014T/ NNTPP/NTA1-SG/2012 Dt Steam Generator & auxiliaries package TA1 for NNTPP (2x500 MW) Euro Million PTE (ICB) 48 months for unit I and 54 months for unit II from the date of LOA for trial operation. Work under progress. 68 M/s BHEL LOA CoConts/0015R/ NNTPS/MTA2TG Dt Turbo Genrator (NTA2)NNTPS PTE (ICB) 42 months for Unit I and 48 Work in progress months for Unit II from LOA date. 69 NSK Builders, Trichy LOA.COCONTS/0014A/ TA/ROADS/CM/2013 dt Alternate road form Neyveli Township to Mandarakuppam 2628 PTE 12 Months from handing over site Work under progress. EOT upto granted with right to levy of LD. 30% of work had been completed. contractor requested EOT for further period upto CGM/TA was addressed on and remined on to expedite the process of approval for further EOT. 70 M/s N.S.K Builders (P) Limited, Trichy. LOA. COCONTS/0019A/TSII EXPN/C02 Gr.II/2013 Dt General Civil works Phase II, Group II roads & Drains in TPS II Expn PTE As on June 15 10% work is completed. EOT upto is granted with right to levy of LD.

9 NAME OF NO. BRIEF DETAILS OF 71 M/s Durga Construction Co. Vadodara LOA.Coconts/0020A/BP/C/M/ OBR/2013 DT OB removal work at Barsingsar PTE 7 Years 23.01% Work under progress. 72 M/s Takraf GMBH Germany & Takraf India, Chennai Contract /Coconts/ 0024A/Man spr.i&ii/modification /2013 dt Modification supply and supervision of replacement of components for Mine II man spr. I & II STE Within 12 months from LOA (i.e ) Engineering completed supplies completed. EOT upto without levy of LD issued on for imported supplies and releasing of second machine after March 2016 with approval of competent authority. 73 M/s Essar Projects India Ltd, Mumbai Co Conts/0031P/NNTPP/NTA3- BOP/2010 Dt Balance of Plant Package (nta3) for NNTPP (2x500MW) GTE 45 months from Work under progress. 74 M/s BHEL, Chennai LOA Coconts/0025A/PV solar Power/CM/13, Dt MW (AC) Solar Power Plant 7460 PTE 9 months from Work under Progress. EOT given upto with right to levy LD. 75 M/s Mahalixmi Infra Contract Pvt Ltd., Ahmedabad LOA CoConts/0021A/ Mine I/OBR/2013 Dt OverBurden Augmentation & debris removal Mine I 9629 PTE 24 months from i.e The agreement quantity of 110 LM3 was enhanced to 128 LM3 with the approval of Competent Authority unde the same tems and conditions including rates. Due to this the contact valu enhanced from Rs crores to crore. The additional quantity has to be carried out within the agreement period already in force. 76 M/s Mining Associates Pvt.Ltd., West Bengal Contract /Coconts/ 0023A/Geology0Drilling /CM/13, Dt Detailed exploration of mts. At 400 mts. Grid interval PTE 18 months from ( i.e. from ) Final survey report not submitted. The extension upto with right to levy LD is under circulation. 77 M/s MSTC Ltd. Cont /COConts/ 0004B/ LTE/NTPL-Coal/2014 Dt Supply of MMT of Imported Coal Non- Cooking (Steaming ) coal of TWO quantities ( Indegenous origin) LTE 120 Days from LOA Note for approval of enhancement of quantity by is under approval. Supply under progress. 78 M/s Thyssen Krupp Idustries India Ltd., Pune LOA Co Conts.0027A/MII BWEs/1571/&1572/ Mech/Rejuvn/13 Dt Rejuvn of BWEs 1571 & 1572 ( for indign Mech Portion) STE Upto end of 29th month from the date of LOA cum Billing schedule under approval. 79 M/s Thyssen Krupp Idustries India Ltd., Pune LOA Co Conts.0027A/MII BWEs/1571/&1572/ Mech/Rejuvn/13 Dt Rejuvn of BWEs 1571 & 1572 ( for imp. Mechl. Portion) Euro 5,219,964 STE Upto end of 29th month from the date of LOA cum Billing schedule under approval.

10 NAME OF NO. BRIEF DETAILS OF 80 M/s Siemens Mumbai LOA Co Conts.0028A/MII BWEs/1571/&1572/ Elecl/Rejuvn/13 Dt Rejuvn of BWEs 1571 & 1572 ( for Elecl. Portion) LTE Upto end of 29th month from the date of LOA cum Billing schedule under approval. 81 M/s BEML, Neyveli PO /Co.Conts/0014B/ M1&MII/Pipelayer/Cont.Mines/20 14, Dt Procurement of 8 Nos. pipe layer of capacity not less than 90T GTE 9 months from i.e under progress. 82 M/s Mahalakshmi Infra Co. Ltd., Ahamedabad 83 M/s.Mecon, Ranchi /Co/Conts/0035B/MII/OB/ Lig/2014 Dt MI and M II LOA CoConts/0008N/ Bithnok PP/Proj. Cons./09, dt Out sourcing of removal of 32LM3 and 8CT Lignite in Mine II Project Consultancy services for Bitnok Power project (1 x 250 MW) PTE INR EURO days from 58 months from LOA Work under progress. Board has accorded approval to extend the contract beyond and to combine the consultancy services for Barsingsar Thermal Power etension project with this contract, by issuing an amendment to the contracts. Amendment has been issued on M/S. TCE Consulting Engg., Bangalore Con.069/10E/HTS II Expn./Cons/2002, dt: Consultancy services for TPS- II Euro PTE EOT granted upto for a revised value of Rs /- + EURO /- excluding service Tax with all other terms and conditions being unaltered. 85 M/s. Lahmeyer International India, Gurgaon LOA Coconts/0020P/ NTPL/2010, dt Consultancy Services for New Thermal Power Project Lakhs PTE Work In progress. 86 M/s Desien Private Ltd., New Delhi LOA CoConts/0010A/ NUPPL/ Proj.consy/2013 dt Project Consultancy services NUPPL for New Thermal Power Project USD PTE (ICB) Work In Progress. 87 M/s. Mecon Ltd, Ranchi LOA.0033J/NTPL (2X500MW)/CT/06 dt Project Consultancy services (Euro Taxes & duties at actuals. PTE 66 months from LOA Note requesting EOT upto with levy of LD for Module 'B' for a value of Rs /- plus EURO excluding Service Tax under circulation. 88 M/s. L&T ST-33/A-79 Maintenance of 3 Nos. of 1400Ltr BWE (L&T-1,2,3), 1 no of 700 Ltr BWE (L&T) and 3 Nos. of MTC's (7,8,9) in MII for three years Three years ( ) 82.9% EOT upto M/s TAKRAF India Pvt Ltd /Co. Conts.0022R/ Cont. IV/VWE /MII Maintenance contract during warranty period for 2 nos of 1400Lit BWE TKF-I : TKF -II: %

11 NAME OF NO. BRIEF DETAILS OF 90 M/s TAKRAF EST-88/A-45 Maintenance of one no,of 4420 Cu M/hr MTC-10 and on no of TPH SPR(SPR -IV) in Mine II for three years % 91 M/s Thyssenkrupp LOI (121)/EST-90/A-14 Maintenance of two nos of 700ltr BWE 1649 & 1650 for three years %. This agreement value includes both BWE 1649 of Mine I and BWE 1650 of Mine II. 92 M/s. Telcon. Co., Chennai /0017/M/M-I,M-II&M-II Expn/Backhoe/2008 dt MII Expansion - Full maintenance contract for 7 years for 7 Nos. of Backhoes PTE % 93 M/s. Telcon. Co., Chennai /0017M/M-I,M-II & M-II Expn./Backhoe/2008 dt MII Expansion - Full maintenance contract for 7 years for 9 Nos. of Backhoes PTE % 94 M/s.Sushee Infra Pvt. Ltd. GM/C/37/11-12 lakhs) (Rs Site grading, deepening of lake, diversion of drain, construction of bridges, surplus weir, check dams etc. for 2x500 MW NNTPS at Neyveli (updated)... 6 months %. As per the recommendation of IIT, Chennai and the committee constituted to study the necessity of Rock toe, the contractor was addressed to carry out the construction of rock toe. 95 M/s.NSK Builders Pvt. Ltd. GM/C/04/12-13 (Rs lakhs) I Suppl GM/C/42/12-13 Rs.2.97 lakhs, 2nd Suppl. Proposal for a value of Rs lakhs approved. Formation of internal roads - Phase-I for 2x500 MW NNTPS at Neyveli. 620 (ori) months 90%. Extension of time upto under process. 96 M/s IVRCL Ltd, Hydrabad LOA NO. 45/NLC/BP/CM/C&P/ T039/S3/11-12 Dt O&M Contract for Water carrier system (for 3 Year) years 100%. O&M contract works completed on M/s Sandeep Enterprises, Gujarat 98 M/s MBECL Kolkatta 99 M/S. TCE Consulting Engg., Bangalore LOA 138/NLC/BTPP/T 140/S1/PTE/BM/LLHS/ Dt A-92/147/NLC/BP/T- 040/S4/O&M/Lignite &Lime handling /STE/11-12 Dt /001G/HTS /PR- CONS/2013 Biennial contract for O&M works of Lignite & Lime Handling system. O&M Contract for Lime and Lignite handling system Consultancy services for BTPP 2x 125 MW), Rajasthan years 25%. Works is under progress years 100%. Work Completed. 695 PTE %. TCE contract is over on further no extension is required. Contract closure activities is under progress.

12 NAME OF NO. BRIEF DETAILS OF 100 M/s BHEL, New Delhi & / 0026H/BPP/ RA1/CONT.Thermal/04, Dt: Main Plant (Supply Erection & Commissioning of Steam Generator Turbo Generator & Auxiliaries RAI) 607,86,52,530 US$ Euro (Rs Crores) Global 100%.Unit 1&2 PG test approved on and 35&29 months Warranty commenced on and completed on from LOA Issue of final taken over certificate is ( ) for PG pending due to in of supply of certain test of unit I & II mandatory spares, tools & tackles documentation respectively and pending works. 101 M/s Mc Nally Bharat Engg. Co. LOA 0027H/BPP/RA2/CT/04, Dt: Lignite and lime stone handling sytem package (RA2) for Barsingsar Power project PTE 31 months from ( ) 99%. Guarantee period is completed on and No demand certificate from NLC side was issued. Arbitration is in progress. 102 M/s Kirloskar Brothers Ltd., Pune. Cont / 0029 H/ BPP/(2x 125 MW)/ RA4/CT/04, Dt: Circulating Water System and Fire Protection System Lakhs PTE Unit I: Unit II: %. Contract closure certificate issued to the firm. 103 M/s Thermax Ltd., Pune LOA 0030H/BPP/RA5/conts. Thermal/04 Dt Water Pre-treatment Plant and D.M. Plant Package (RA5) for Barsingsar Project, Rajasthan PTE 32 months from LOA dt %. Contract closure certificate issued to the firm. 104 M/s Gammon India Ltd., Mumbai LOA 0031H/BPP/RA6/CT/04 Dt Induced draft cooling towers and RCC Bi-flue Chimney for Barsingsar project, Rajasthan 3888 PTE %. PG test successfully completed and Final Take over done on for IDCTs and for CHIMNEY. DLP period completed. Finalisation of package is in progress. 105 M/s BHEL, New Delhi Cont & / 0032 H/BPP/RA7/CT/04, dt for supply & services respectively 220 KV switch yard & Power Transformers Package (RA7) for BTPP (2 x 125 MW) Rajasthan 7128 PTE 20 months from i.e., upto %. No demand certificate was issued on and No claim certificate is yet to be issued by the contractor. Financial reconciliation and no claim certificate are being pursued with M/s BHEL TBG. 106 M/S IVRCL, I&P LTD Hyderabad /0033H/BPP/RA8/cont/th ermal/04 dt Water Carrier system 7997 PTE % Final reconciliation completed and conditional no claim certificate was received. Appeal has been filed by NLC against arbitration award. 107 M/s Diamond Infra Construction (P) Ltd., Chennai. GM/MI/NAMC/MSU/A34/ /Agt. 01/15-16 Construction of Belt Reconditioning Plant including internal electrification in Mine II area PTE % of agt. Value completed 108 Shri. C. Vadivelu Contractor Agt. CGM/M-II/SMD/PT-58/A- 153/ Permanent diversion of Paravanar along LA boundary including formation of bund Lakhs ( EOT sanctioned upto )

13 NAME OF NO. BRIEF DETAILS OF 109 M/s Ayyakkannu & Co Neyveli Agt Transportation of ash slag clinkers from Boiler areas of Units 1 to 7 in TPS II PTE 730 days from the date of commencement of work % of work carried out upto